Solution-Write a letter replying to the extract of the

Write a letter replying to the extract of the letter

Reference no: EM131038769 , Length: 900 Words

Assignment Task

Outback Contractors have won a fixed price contract to construct a new National Football Stadium (The works comprise; (1) Football stadium; (2) Leisure facilities; (3) Restaurants; (4) Concourse) with works commencing on 1 February 2015 and the Employer is to take over control of the site on 31 January 2016. Letters are sent during the contract from the Contractor to the Employers agent as in the following table.

Table 1: Extract from Outback Contractors letter

Date

Extract from Outback Contractors letter

14 March 2015

With regard to your email of today we note that Section c of the site will not be provided to us at the beginning of next week as agreed as the current occupants (Traders) have not vacated the site.

Whilst we understand that problems have arisen owing to the occupants' unauthorized illegal actions and that you hope to have the matter resolved shortly, it will cause delay in relation to our programme and we will incur loss and expense.

We shall revise our programme (as requested) and will endeavour to limit our loss.

You are required to do the following:
- Write a letter replying to the Extract of the letter of 14 March 2015
- In the report discuss the contractual reasoning behind your responses under JCT Standard Building Contract.

Verified Expert

This is a reponse letter to the contractors extract of the letter over a issue regarding the vacancy of illegal occupants in the planned construction site.

Reference no: EM131038769

Questions Cloud

Prepare a definition of a disability for strong company : Prepare a definition of a disability for Strong Company. Include examples of disabilities and examples of those things that would not be considered disabilities.

Prepare a strong company anti-discrimination policy : Prepare a Strong Company anti-discrimination policy. Include information that an employee should consider in waiving his or her rights under ADEA. Be sure to consider and include concepts from previous modules. As always, it is important to cite ..

How law shaped and developed and limits of legal controls : Would your answer be different if you were told that Jennifer was an independent contractor and not an employee of ParcelEasy? Justify your answer.

Identify legal issues arising out of novel factual situation : Identify the legal issues arising out of novel factual situations, to analyse the applicable law and to differentiate between which rules are applicable and which are not and then apply the law to the problem;

Write a letter replying to the extract of the letter : Write a letter replying to the Extract of the letter of 14 March 2015 and in the report discuss the contractual reasoning behind your responses under JCT Standard Building Contract.

How would the auditor be aware of such events : What are the concerns that lead the auditor to physically observe inventory? Do you think observing only a sample of inventory is sufficient? Why or why not?

How much will that car have cost in four years : What will your payment be to your local bank, assuming your 10% down payment? (Be sure to use the formula and show your work).

Behaves with remarkable sensitivity and understanding : At certain points in this novel, Jesse behaves with remarkable sensitivity and understanding for a person of his age. Other times, he seems immature and uncertain of his place in the adult world. How do Jesse's feelings about and interactions with..

What types of information will the court review : What standard will the court apply to address evidence of the claim? Have the plaintiffs stated a valid claim under Rule 10b-5 and section 10(b), or will the court grant PEM's motion to dismiss?

User Account

All Pages

Write a letter replying to the extract of the letter

Reference no: EM131038769 , Length: 900 Words

Reference no: EM131038769

Questions Cloud

Reviews

Write a Review

Civil Engineering Questions & Answers

Engineering ethics and ethical issue

Engineering ethics and concept and cases

Transportation and management

Supporting Investment Promotion: ERNST & YOUNG

Personalized Cancer Therapy-A step forward

Discuss the different environmental companies

Develop a simple urban constructed wetland design

Evaluate company performance in relation to GRI standards

Water system design

Hydraulic behaviour in open channel

Write a paper on steel sustainability

Writing case study about bridge collapse

Assured A++ Grade

Academics

Major Subjects

Majors

Get In Touch

TERMS & POLICIES

HELP & SUPPORT